House Study Bill 741 HOUSE FILE BY (PROPOSED COMMITTEE ON COMMERCE, REGULATION AND LABOR BILL BY CHAIRPERSON JENKINS) Passed House, Date Passed Senate, Date Vote: Ayes Nays Vote: Ayes Nays Approved A BILL FOR 1 An Act relating to deficiencies in the construction or design of 2 residential real property. 3 BE IT ENACTED BY THE GENERAL ASSEMBLY OF THE STATE OF IOWA: 4 TLSB 6509HC 81 5 kk/je/5 PAG LIN 1 1 Section 1. NEW SECTION. 657B.1 DEFINITIONS. 1 2 1. "Builder" includes a builder, developer, or original 1 3 seller of residential real property that is sold on or after 1 4 July 1, 2006. 1 5 2. "Claimant" means an individual owner of residential 1 6 real property and includes an owner of a condominium unit and 1 7 an association of a common interest community. "Claimant" 1 8 does not include a person not in privity of contract with a 1 9 builder. 1 10 3. "Residential real property" means real property which 1 11 is an owner=occupied single=family or two=family dwelling, 1 12 located in this state, occupied or used or intended to be 1 13 occupied or used for residential purposes, including an 1 14 interest in any real property covered under chapter 499B. 1 15 Sec. 2. NEW SECTION. 657B.2 NOTICE OF CLAIM. 1 16 Prior to filing an action for the recovery of damages 1 17 arising out of, or related to, a deficiency in the 1 18 construction, design, specifications, survey, plan, 1 19 supervision, testing, or observation of construction of 1 20 residential real property against a builder, the claimant 1 21 shall provide written notice by certified mail or personal 1 22 service to the builder that the construction, design, 1 23 specifications, survey, plan, supervision, testing, or 1 24 observation of construction of the claimant's residence is 1 25 deficient or violates an applicable housing code or city 1 26 ordinance. The notice shall state the claimant's name, 1 27 address, and contact information. The notice shall also state 1 28 that the claimant alleges a deficiency or violation against 1 29 the builder and shall describe the nature of the claim in 1 30 sufficient detail for the builder to determine the nature and 1 31 location of the alleged deficiency or violation. 1 32 Sec. 3. NEW SECTION. 657B.3 BUILDER REQUIREMENTS. 1 33 1. A builder who receives notice pursuant to section 1 34 657B.2 shall provide the claimant a written acknowledgment of 1 35 receipt of the claimant's notice of claim within ten business 2 1 days after receiving the notice of claim. 2 2 2. Prior to the transfer of title of newly constructed 2 3 residential real property, the builder shall provide written 2 4 notice to the purchaser of the availability of mediation 2 5 services pursuant to chapter 679C. After receiving a notice 2 6 pursuant to this subsection, the purchaser shall provide the 2 7 builder with written acknowledgment of receiving the notice. 2 8 Sec. 4. NEW SECTION. 657B.4 BUILDER'S OFFER TO REPAIR. 2 9 Within ten business days after the builder provides an 2 10 acknowledgment of the claimant's notice of claim pursuant to 2 11 section 657B.3, the builder may offer in writing to compensate 2 12 the claimant or repair the deficiency. An offer to compensate 2 13 the claimant shall be a bona fide offer to compensate the 2 14 claimant for damages to the residential real property of the 2 15 claimant. An offer to repair the deficiency shall include a 2 16 detailed statement identifying the particular deficiency to be 2 17 repaired, an explanation of the nature, scope, and location of 2 18 the repair needed, and an estimated completion date of the 2 19 repair which shall be within twenty=one business days of the 2 20 builder's receipt of the notice of claim, assuming reasonable 2 21 weather=related construction conditions, or as otherwise 2 22 agreed to by the parties. 2 23 Sec. 5. NEW SECTION. 657B.5 CLAIMANT'S REMEDIES. 2 24 1. A claimant shall not file an action for the recovery of 2 25 damages arising out of, or related to, deficiencies in the 2 26 construction, design, specifications, survey, plan, 2 27 supervision, testing, or observation of construction of 2 28 residential real property against a builder, unless the 2 29 claimant has provided a notice of claim as required by section 2 30 657B.2 and the builder fails to do any of the following: 2 31 a. Make an offer to compensate the claimant or repair a 2 32 deficiency in compliance with section 657B.4. 2 33 b. Compensate a claimant or perform an adequate repair to 2 34 correct the deficiency after making an offer to compensate or 2 35 repair under section 657B.4, which is accepted by the 3 1 claimant. 3 2 c. Complete a repair within the time required by section 3 3 657B.4. 3 4 d. Comply with any other requirement of this chapter. 3 5 2. This section does not preclude a claimant from seeking 3 6 remedies available through a customer service procedure 3 7 described in a contract, warranty, or other document provided 3 8 by the builder. 3 9 Sec. 6. NEW SECTION. 657B.6 STATUTE OF LIMITATIONS. 3 10 If a builder makes an offer to repair pursuant to section 3 11 657B.4, the provision of a notice of claim pursuant to section 3 12 657B.2 tolls any applicable statute of limitations from the 3 13 date of service of the notice of claim through the estimated 3 14 completion date of the repair. 3 15 EXPLANATION 3 16 This bill relates to deficiencies in residential real 3 17 property. The bill requires a claimant, as defined by the 3 18 bill, to provide a builder of residential real property with a 3 19 notice of a claim against the builder prior to commencing an 3 20 action against the builder for damages arising from 3 21 deficiencies in the construction, design, specifications, 3 22 survey, plan, supervision, testing, or observation of 3 23 construction of the residential real property. The notice of 3 24 claim is required by the bill to state the claimant's name, 3 25 address, and contact information, and to describe in detail 3 26 the nature of the violation alleged against the builder. 3 27 The bill requires builders to provide a claimant with a 3 28 written acknowledgment within 10 days after receiving the 3 29 notice of claim. The bill requires builders to provide a 3 30 written notice to any claimant of the availability of 3 31 mediation services. A claimant who receives a notice of 3 32 available mediation services shall provide the builder an 3 33 acknowledgment of receiving the notice. 3 34 The bill allows a builder to offer to compensate the 3 35 claimant for a deficiency or repair the deficiency. The offer 4 1 to compensate or repair must be made within 10 business days 4 2 after the builder provides an acknowledgment of the claimant's 4 3 notice of claim. An offer to compensate must be a bona fide 4 4 offer and an offer to repair must include a detailed statement 4 5 identifying the particular deficiency to be repaired, an 4 6 explanation of the nature, scope, and location of the repair, 4 7 and an estimated completion date of the repair. The estimated 4 8 completion date of the repair is required by the bill to be 4 9 within 21 days of the builder's receipt of the notice of 4 10 claim, within reasonable weather conditions, or as otherwise 4 11 agreed to by the parties. 4 12 The bill prohibits a claimant from filing an action for 4 13 damages from deficiencies in construction, design, 4 14 specifications, survey, plan, supervision, testing, or 4 15 observation of construction of residential real property 4 16 against a builder unless the claimant has provided a notice of 4 17 claim to the builder and the builder has failed to make an 4 18 offer to compensate or repair as provided by the bill, failed 4 19 to compensate or perform an adequate repair, failed to 4 20 complete a repair within the time required by the bill, or 4 21 failed to comply with any other provision of the bill. The 4 22 bill does not prohibit a claimant from otherwise seeking other 4 23 remedies available by contract, warranty, or a similar 4 24 customer service remedy provided by the builder. 4 25 The bill provides that if a builder makes an offer to 4 26 repair as provided by the bill, the applicable statute of 4 27 limitations is tolled from the date of the service of the 4 28 notice of claim to the estimated completion date of the 4 29 repair. 4 30 LSB 6509HC 81 4 31 kk:nh/je/5