House File 2722 - Introduced HOUSE FILE BY COMMITTEE ON COMMERCE, REGULATION AND LABOR (SUCCESSOR TO HSB 741) Passed House, Date Passed Senate, Date Vote: Ayes Nays Vote: Ayes Nays Approved A BILL FOR 1 An Act relating to deficiencies in the construction or design of 2 residential real property. 3 BE IT ENACTED BY THE GENERAL ASSEMBLY OF THE STATE OF IOWA: 4 TLSB 6509HV 81 5 kk/je/5 PAG LIN 1 1 Section 1. NEW SECTION. 657B.1 DEFINITIONS. 1 2 For the purposes of this chapter, the following definitions 1 3 shall apply: 1 4 1. "Builder" means a builder or developer of a new 1 5 residential unit that is sold on or after July 1, 2006. 1 6 2. "Claimant" includes an individual owner of a single= 1 7 family home, an individual unit owner of an attached dwelling, 1 8 and, in the case of a common interest development, an 1 9 association. "Claimant" does not include a person not in 1 10 privity of contract with a builder. 1 11 Sec. 2. NEW SECTION. 657B.2 NOTICE OF CLAIM. 1 12 1. Prior to filing an action for recovery of property 1 13 damages arising out of, or related to deficiencies in, the 1 14 residential construction, design, specifications, survey, 1 15 plan, supervision, testing, or observation of construction 1 16 against a builder, the claimant shall provide written notice 1 17 by certified mail, overnight mail, or personal delivery to the 1 18 builder that the construction, design, specifications, survey, 1 19 plan, supervision, testing, or observation of construction of 1 20 the claimant's residence is deficient or violates the 1 21 applicable housing code or city ordinance. The notice shall 1 22 state the claimant's name, address, and contact information, 1 23 and shall describe the nature of the claim in sufficient 1 24 detail in order to determine the nature and location of the 1 25 alleged violation. The document shall have the same force and 1 26 effect as a notice of commencement of a lawsuit. 1 27 2. The notice requirements of this section do not preclude 1 28 a claimant from seeking redress through a customer service 1 29 procedure set forth in a contract, warranty, or other document 1 30 generated by the builder. 1 31 Sec. 3. NEW SECTION. 657B.3 BUILDER'S RECEIPT OF CLAIM 1 32 == ACKNOWLEDGEMENT. 1 33 Within ten days of receipt of a claimant's notice of claim, 1 34 the builder shall provide the claimant a written 1 35 acknowledgement of receipt of the claim by certified mail, 2 1 overnight mail, or personal delivery. 2 2 Sec. 4. NEW SECTION. 657B.4 REPAIRS. 2 3 Within ten business days of the builder's acknowledgment of 2 4 a claimant's notice of claim, the builder may make an offer in 2 5 writing which shall include either of the following: 2 6 1. A bona fide offer to compensate the claimant for repair 2 7 of the defect and property damages caused by the defect. 2 8 2. An offer to repair with a detailed statement 2 9 identifying the particular deficiency to be repaired, an 2 10 explanation of the nature, scope, and location of the repair 2 11 needed, and the estimated completion date of the repair, which 2 12 shall occur within either twenty=one business days of the 2 13 builder's receipt of the claimant's notice of claim, or within 2 14 reasonable weather=related construction conditions, or as 2 15 otherwise agreed to by the parties. 2 16 Sec. 5. NEW SECTION. 657B.5 CIVIL ACTION. 2 17 A claimant may file an action seeking recovery of damages 2 18 against a builder if the builder does any of the following: 2 19 1. Fails to make an offer to repair, performs an 2 20 inadequate repair, or does not complete a repair within a 2 21 reasonable period of time. 2 22 2. Fails to comply with any other requirement of this 2 23 chapter. 2 24 Sec. 6. NEW SECTION. 657B.6 STATUTE OF LIMITATIONS. 2 25 If a builder makes an offer to repair pursuant to section 2 26 657B.4, the provision of a notice of claim pursuant to section 2 27 657B.2 tolls any applicable statute of limitations from the 2 28 date of service of the notice of claim through the estimated 2 29 completion date of the repair. 2 30 EXPLANATION 2 31 This bill relates to deficiencies in residential real 2 32 property. The bill requires a claimant, as defined by the 2 33 bill, to provide a builder of residential real property with a 2 34 notice of a claim against the builder prior to commencing an 2 35 action against the builder for property damages arising from 3 1 deficiencies in the construction, design, specifications, 3 2 survey, plan, supervision, testing, or observation of 3 3 construction of the residential real property. The notice of 3 4 claim is required by the bill to state the claimant's name, 3 5 address, and contact information, and to describe in detail 3 6 the nature and location of the violation alleged against the 3 7 builder. 3 8 The bill requires builders to provide a claimant with a 3 9 written acknowledgment within 10 days after receiving the 3 10 notice of claim. 3 11 The bill allows a builder to offer to compensate the 3 12 claimant for a deficiency or repair the deficiency. The offer 3 13 to compensate or repair must be made within 10 business days 3 14 after the builder provides an acknowledgment of the claimant's 3 15 notice of claim. An offer to compensate must be a bona fide 3 16 offer and an offer to repair must include a detailed statement 3 17 identifying the particular deficiency to be repaired, an 3 18 explanation of the nature, scope, and location of the repair, 3 19 and an estimated completion date of the repair. The estimated 3 20 completion date of the repair is required by the bill to be 3 21 within 21 days of the builder's receipt of the notice of 3 22 claim, within reasonable weather conditions, or as otherwise 3 23 agreed to by the parties. 3 24 The bill provides that a claimant may file an action for 3 25 damages against a builder if the builder has failed to make an 3 26 offer to repair as provided by the bill, performed an 3 27 inadequate repair, failed to complete a repair within a 3 28 reasonable time, or failed to comply with any other provision 3 29 of the bill. The bill does not prohibit a claimant from 3 30 otherwise seeking other remedies available by contract, 3 31 warranty, or a similar customer service remedy provided by the 3 32 builder. 3 33 The bill provides that if a builder makes an offer to 3 34 repair as provided by the bill, the applicable statute of 3 35 limitations is tolled from the date of the service of the 4 1 notice of claim to the estimated completion date of the 4 2 repair. 4 3 LSB 6509HV 81 4 4 kk:nh/je/5